Home / Browse projects / Thane, Maharashtra / SHETH CNERGY PH 1 - UPTO 11TH FLOOR
SHETH CNERGY PH 1 - UPTO 11TH FLOOR
By Sheth Developers Private Limited
RG-MH-15789 · RERA P51700023047 · Last updated on MahaRERA portal: 5 May 2026
Source: official MahaRERA filing
Or get an email each time it changes, with the project watch
Red flags
- Litigation declared, 1 case
- 4 complaints at MahaRERA
- Completion date moved by 48 months
- 2 extensions taken
- Rs 85.00 crore secured on the land, in favour of VIVRITI CAPITAL LIMITED
Clear
- Separate project account declared
- Allotment letter follows the model form
5 conditions are on this record. What each one means for someone buying here, and what the promoter's own filed documents say behind it, is what the buyer report adds.
See what the report covers Free either way: or have every new Thane registration emailed to you, free during the pilot beta.Saved. When you are ready to decide, the Rs 499 buyer report reads the fine print for you.
SHETH CNERGY PH 1 - UPTO 11TH FLOOR is a Commercial project by Sheth Developers Private Limited in Thane, Maharashtra, registered with MahaRERA as P51700023047 on 18 Nov 2019. Possession is promised by 28 Dec 2027. The completion date has moved by 48 months from the original filing. 149 of the 173 units on this registration are recorded sold or booked, and 4 of 11 construction stages are filed complete. 4 complaints are on record with the regulator.
At a glance
Project
- NameSHETH CNERGY PH 1 - UPTO 11TH FLOOR
- TypeCommercial
- Location
- EASTERN EXPRESS HIGHWAY
- PANCH PAKHADI
- Thane (M Corp.)
- Thane
- 400601
- Pincode400601
- MapView location on Google Maps (as filed on RERA)
- RERA no.P51700023047
- ReraGenie IDRG-MH-15789
Key dates
Key facts
Registration and timeline
- StatusRegistered
- Registered on18 Nov 2019
- Promised completion28 Dec 2027
- Revised completionRevised to 28 Dec 2027 (originally 30 Dec 2023)
- Buildings1 building record
- Documents filed133 files
Current status
Figures as on 5 May 2026, this project's latest MahaRERA filing.
Buildings and wings, as sanctioned
| Building | Wing | Floors sanctioned | Habitable floors | Residential units | Other units | Total |
|---|---|---|---|---|---|---|
| SHETH CNERGY | NA | 7 | 7 | 0 | 173 | 173 |
The full filing
Everything below is from the project's own MahaRERA filing, free to read. The Rs 499 buyer report reads the filed documents themselves and puts the findings in plain language.
Construction progress by building1
As on 5 May 2026, the date of the latest filing. The RERA activity checklist for each building, from the promoter's latest quarterly progress filing. These are the promoter's own figures, not an independent inspection.
4 of 11 construction stages are filed complete. The stage furthest along is Slabs of Super Structure, at 41%.
SHETH CNERGY: 41% average across the applicable activities
| Activity | Progress |
|---|---|
| Excavation | 100% |
| Basement (if any) | 100% |
| Podiums (if any) | 0% |
| Plinth | 100% |
| Stilt Floor | 100% |
| Slabs of Super Structure | 41% |
| Internal walls, Intemal Plaster, Floorings, Floors and windows within Flats/Premises | 5% |
| Sanitary Fittings within the flats / premises | 0% |
| Staircases, Lifts Wells and Lobbies at each Floor level Overhead and Underground Water Tanks | 0% |
| External plumbing and external plaster, elevation, completion of terraces with waterproofing of the Building / wing. | 0% |
| Installation of Lifts, water pumps, Fire Fighting Fittings and Equipment as per CFO NOC, Electrical fittings, mechanical equipment, compliance to conditions ofenvironment/CRZ NOC, Finishing to entrance lobby/s, plinth protection. paving of areas appurtenant to Building/Wing, Compound Wall and all other requirements as may be required to complete project as per specifications in agreement of Sale. | 0% |
Progress on shared amenities15
As on 5 May 2026, the date of the latest filing. Lifts, roads, water and the other shared works, from the same quarterly filing, and reported by the promoter rather than inspected.
| Common facility | Proposed | Progress |
|---|---|---|
| Internal Roads & Footpaths | No | Not applicable |
| Water Supply | Yes | 0% |
| Sewerage (Chamber, Lines, Septic Tank , STP) | Yes | 0% |
| Storm Water Drains | Yes | 0% |
| Landscaping & Tree Planting | Yes | 0% |
| Street Lighting | No | Not applicable |
| Community Buildings | No | Not applicable |
| Treatment And Disposal Of Sewage And Sullage Water | Yes | 0% |
| Solid Waste Management And Disposal | Yes | 0% |
| Water conservation /Rain water harvesting | Yes | 0% |
| Energy managemcnt | Yes | 0% |
| Fire protection and fire safety requirements | Yes | 20% |
| Electrical meter room, sub-station, receiving station | Yes | 0% |
| Aggregate area of recreational Open Space | Yes | 0% |
| Open Parking | No | Not applicable |
Parking filed353
Slots recorded per building wing in the filing. MahaRERA does not publish a two wheeler or four wheeler split, visitor parking, or the sanctioned allotment, so this is provision as filed and not a comparison against the approved plan.
Land and ownership
A declared charge means a lender has a claim over the project land. Ask the promoter for a no-objection certificate from the lender named above before you pay any amount.
Approvals and building plan
Project account and cost
70 percent of buyer money must sit in the project account. Account numbers are not published by MahaRERA, so check that your agreement for sale names a designated account for this project and pay into that account only.
| Building | Wing | Estimated | Incurred |
|---|---|---|---|
| SHETH CNERGY | NA | Rs 54.87 cr | Rs 40.76 cr |
| - | NA | Rs 5.58 cr | - |
Certifying professionals and partners11
Form 1, 2 and 3 certificates from these professionals release the promoter's withdrawals from the 70 percent account.
| Role | Name |
|---|---|
| Architect | Bipin Nannaware |
| Architect | TEN FOLDS ARCHITECTS AND CONSULTANTS |
| Engineer | Muhammad Shoeb Chouhan |
| Engineer | Umesh N Tripathi |
| Engineer | Smarty Lachhwani |
| Engineer | Anas Shaikh |
| Engineer | Mr.Sandeep Magam |
| Chartered Accountant | M B AGRAWAL & CO. |
| Chartered Accountant | Haresh Bhanushali |
| Chartered Accountant | Haresh Bhanushali and Associates |
| Chartered Accountant | Mr. Haresh Bhanushali |
| Partner | Role in project |
|---|---|
| Sheth Developers Private Limited | - |
Extensions applied for2
A revised date filed with the regulator does not change the possession date in your agreement for sale.
Reason as filed by the promoterThe applicant vide Development Agreement dated 01.10.2003 executed between Voltas Limited and the applicant, acquired rights to develop a land admeasuring aggregating to 1,15,018 sq. mtrs. The Applicant state out of the bigger property the land bearing Survey No. 35/4A admeasuring 434 sq. mtrs., land bearing Survey No. 35/8 admeasuring 5236.17 sq. mtrs., and land bearing survey no. 35/9/A admeasuring 746.30 sq. mtrs., was affected by Fire Bridget Station and MTRS reservation as per the sanctioned Development Plan for the City of Thane. Thane Municipal Corporation permitted the applicant to dev
Reason as filed by the promoterThe applicant vide Development Agreement dated 01.10.2003 executed between Voltas Limited and the applicant, registered at the office of sub-registrar Thane at Serial No. TNN1/06589/2003 on 03.10.2003 acquired rights to develop a land admeasuring aggregating to 1,15,018 sq. mtrs. The Applicant state out of the bigger property the land bearing Survey No. 35/4A admeasuring 434 sq. mtrs., land bearing Survey No. 35/8 admeasuring 5236.17 sq. mtrs., and land bearing survey no. 35/9/A admeasuring 746.30 sq. mtrs., (Hereinafter referred to as “The entire property”) was affected by Fire Bridget Statio
Litigation declared1
| Case | Court | Status |
|---|---|---|
| CP/320/2024/2024 | Bombay High Court | Ongoing |
Complaints filed with MahaRERA4
| Case no. | Complainant | Respondent | Filed |
|---|---|---|---|
| CC12500459 | SUNIL BABAN SHINDE | Sheth Developers Private Limited | 11/02/2025 |
| CC12500650 | Sanjay Thakur | Sheth Developers Private Limited | 24/02/2025 |
| CC12500652 | Sanjay Thakur | Sheth Developers Private Limited | 24/02/2025 |
| CC12503592 | sunil patil | Sheth Developers Private Limited | 08/10/2025 |
The permission chain
The permissions a project needs, in the order they happen, matched to MahaRERA's own document slots. A slot on the file means the promoter uploaded a document there; it is not proof the permission was granted, and the filing carries no issue dates. An empty slot is not proof an approval is missing.
- Legal title reportOn the file
A lawyer's report on who owns the land and what is registered against it.
uploaded 5 Nov 2019 - Layout approvalOn the file
The planning authority's approval of how the plots and buildings sit on the land.
uploaded 26 Dec 2023 - Building plan approvalOn the file
Sanction of the building plans themselves, filed as an IOD in Mumbai and as a plan approval elsewhere.
uploaded 26 Dec 2023 - Commencement CertificateOn the file
Permission to begin construction. On a plotted development the same slot carries the NA order instead.
uploaded 19 Jul 2024Confirm the Commencement Certificate covers the specific floor you are buying. - Occupancy CertificateNot due yet
The legal go-ahead to move in. It comes at the end, so its absence on a project still under construction is expected.
possession is promised for 28 Dec 2027
Documents filed133
As listed on the registration, named by the MahaRERA slot each file was filed under, with the promoter's own file name beneath; the newest 80 of 133 are shown. The files themselves are available at source: open this registration on the MahaRERA portal. We publish what the filing says and never host the promoter's documents in place of it.
| Document | Uploaded |
|---|---|
| Withdrawal Update Form 1File: CNERGY Thane Phase-2 Architects Certificate FORM -1.pdf | 5 May 2026 |
| Withdrawal Update Form 2File: SHETH CNERGY PH 1.pdf | 5 May 2026 |
| Withdrawal Update Form 3File: Form - 3_Cnergy Thane_Mar 26.pdf | 5 May 2026 |
| Withdrawal Update Form 1File: FORM 1 CNERGY THANE PHASE 1.pdf | 28 Jan 2026 |
| Withdrawal Update Form 2File: SHETH CNERGY PH-1.pdf | 28 Jan 2026 |
| Withdrawal Update Form 3File: Form-3_Cnergy Thane_Dec 25_Signed.pdf | 28 Jan 2026 |
| Form 5 (FY 2024-2025)File: Form - 5_Cnergy Thane_2024-25-Signed.pdf | 25 Nov 2025 |
| Withdrawal Update Form 1File: FORM-1 - Sheth Cnergy ph 1.pdf | 21 Nov 2025 |
| Withdrawal Update Form 2File: FORM 2 - SHETH CNERGY PH 1.pdf | 21 Nov 2025 |
| Withdrawal Update Form 3File: Signed Form-3 Cnergy_Thane_Sept_2025.pdf | 21 Nov 2025 |
| Form 2A (FY 2024-2025)File: FORM-2A - CENRGY PH -1.pdf | 5 Nov 2025 |
| Withdrawal Update Form 1File: Form 1 - Cnergy Thane PH 1.pdf | 29 Sep 2025 |
| Withdrawal Update Form 2File: Form - 2 Cnergy Thane.pdf | 29 Sep 2025 |
| Withdrawal Update Form 3File: Form - 3 Cnergy Thane.pdf | 29 Sep 2025 |
| Cnergy Thane | 29 Apr 2025 |
| CA Certificate on Project Cost & Fund withdrawal (Form 3)File: FORM 3 - Sheth Cengry Phase-I.pdf | 29 Apr 2025 |
| FORM 2 - Sheth Cnergy | 29 Apr 2025 |
| Disclosure of sold/ booked inventoryFile: SHETH CNERGY-THANE 1.pdf | 29 Apr 2025 |
| Disclosure of sold/ booked inventoryFile: CNERGY-THANE.pdf | 22 Jan 2025 |
| Architect’s Certificate of Percentage of Completion of Work (Form 1)File: Cnergy Thane.pdf | 18 Jan 2025 |
| CA Certificate on Project Cost & Fund withdrawal (Form 3)File: FORM-3- Sheth Cnergy Phase-I.pdf | 16 Jan 2025 |
| Engineer’s Certificate on Cost Incurred on Project (Form 2)File: FORM-2 - Sheth Cnergy-Thane.pdf | 16 Jan 2025 |
| Architect’s Certificate of Percentage of Completion of Work (Form 1)File: CNERGY-PH 1--FORM -1-Architect Certificate.pdf | 29 Oct 2024 |
| CA Certificate on Project Cost & Fund withdrawal (Form 3)File: Form - 3 Cynergy Thane.pdf | 29 Oct 2024 |
| Engineer’s Certificate on Cost Incurred on Project (Form 2)File: Form - 2 Cnergy Thane.pdf | 29 Oct 2024 |
| Disclosure of sold/ booked inventoryFile: CNERGY THANE.pdf | 29 Oct 2024 |
| Annual Audit Report of Statutory CA (Form 5) (FY 2023-24)File: FORM-5 - SHETH CNERGY-THANE.pdf | 8 Oct 2024 |
| Annual Audit Report of Statutory CA (Form 5) (FY 2023-24)File: FORM-5 - SHETH CNERGY THANE.pdf | 8 Oct 2024 |
| Form 5 (FY 2023-2024)File: FORM-5 - SHETH CNERGY THANE.pdf | 30 Sep 2024 |
| Disclosure of sold/ booked inventoryFile: CNERGY-THANE.pdf | 31 Jul 2024 |
| Architect’s Certificate of Percentage of Completion of Work (Form 1)File: Form 1 - Cnergy Thane.pdf | 26 Jul 2024 |
| Engineer’s Certificate on Cost Incurred on Project (Form 2)File: FORM -2 - SHETH CNERGY.pdf | 26 Jul 2024 |
| CA Certificate on Project Cost & Fund withdrawal (Form 3)File: FORM -3 -SHETH CNERGY PHASE-I.pdf | 26 Jul 2024 |
| Commencement Certificates / NA Order for plotted developmentFile: CC Cnergy Thane 4 AND 5 FLOOR.pdf | 19 Jul 2024 |
| Declaration about Commencement CertificateFile: Declaration about Commencement Certificate Cnergy Thane.pdf | 19 Jul 2024 |
| Disclosure of sold/ booked inventoryFile: CNERGY THANE.pdf | 6 May 2024 |
| Engineers Certificate on Quality Assurance (Form 2A FY 2023-24)File: 1.pdf | 3 May 2024 |
| Engineers Certificate on Quality Assurance (Form 2A FY 2023-24)File: 2.pdf | 3 May 2024 |
| Engineers Certificate on Quality Assurance (Form 2A FY 2023-24)File: 3.pdf | 3 May 2024 |
| Engineers Certificate on Quality Assurance (Form 2A FY 2023-24)File: 4.pdf | 3 May 2024 |
| Architect’s Certificate of Percentage of Completion of Work (Form 1)File: Form 1 - Cnergy Thane.pdf | 23 Apr 2024 |
| Engineer’s Certificate on Cost Incurred on Project (Form 2)File: FORM-2 - Sheth Cnergy.pdf | 22 Apr 2024 |
| CA Certificate on Project Cost & Fund withdrawal (Form 3)File: FORM-3 - Cnergy Thane.pdf | 22 Apr 2024 |
| Disclosure of sold/ booked inventoryFile: CNERGY THANE (1).pdf | 31 Jan 2024 |
| Architect’s Certificate of Percentage of Completion of Work (Form 1)File: Form- 1 Cnergy Thane.pdf | 16 Jan 2024 |
| Engineer’s Certificate on Cost Incurred on Project (Form 2)File: Form - 2 - Cnergy Thane.pdf | 16 Jan 2024 |
| CA Certificate on Project Cost & Fund withdrawal (Form 3)File: Form - 3 - Cnergy Thane.pdf | 16 Jan 2024 |
| Building plan approvalFile: IOA.pdf | 26 Dec 2023 |
| Layout approvalFile: 1.pdf | 26 Dec 2023 |
| Layout approvalFile: 2.pdf | 26 Dec 2023 |
| Layout approvalFile: 3.pdf | 26 Dec 2023 |
| Copy of Layout Approval (in case of layout)File: 1.pdf | 26 Dec 2023 |
| Copy of Layout Approval (in case of layout)File: 2.pdf | 26 Dec 2023 |
| Copy of Layout Approval (in case of layout)File: 3.pdf | 26 Dec 2023 |
| Building Plan Approval / NA Order for plotted developmentFile: IOA.pdf | 26 Dec 2023 |
| Commencement Certificates / NA Order for plotted developmentFile: Revised Cc.pdf | 14 Dec 2023 |
| Declaration about Commencement CertificateFile: CC Declaration.pdf | 14 Dec 2023 |
| Declaration in FORM BFile: Form B.pdf | 14 Dec 2023 |
| Engineers Certificate on Quality Assurance (Form 2A FY 2022-23)File: 1) 1st quater.pdf | 7 Dec 2023 |
| Engineers Certificate on Quality Assurance (Form 2A FY 2022-23)File: 2) 2nd quater.pdf | 7 Dec 2023 |
| Engineers Certificate on Quality Assurance (Form 2A FY 2022-23)File: 3) 3rd quater.pdf | 7 Dec 2023 |
| Engineers Certificate on Quality Assurance (Form 2A FY 2022-23)File: 4) 4th quater.pdf | 7 Dec 2023 |
| Disclosure of sold/ booked inventoryFile: CNERGY THANE (1).pdf | 27 Nov 2023 |
| Architect’s Certificate of Percentage of Completion of Work (Form 1)File: Form - 1 Cnergy Phase 1 ( Thane ).pdf | 18 Oct 2023 |
| Engineer’s Certificate on Cost Incurred on Project (Form 2)File: Form - 2 Cnergy Thane.pdf | 18 Oct 2023 |
| CA Certificate on Project Cost & Fund withdrawal (Form 3)File: Form - 3 - Cnergy Thane.pdf | 18 Oct 2023 |
| Annual Audit Report of Statutory CA (Form 5) (FY 2022-23)File: FORM-5 - SHETH CNERGY-THANE.pdf | 8 Sep 2023 |
| Engineer’s Certificate on Cost Incurred on Project (Form 2)File: FORM-2 CNERGY THANE.pdf | 19 Jul 2023 |
| CA Certificate on Project Cost & Fund withdrawal (Form 3)File: FORM-3 CNERGY THANE.pdf | 19 Jul 2023 |
| Architect’s Certificate of Percentage of Completion of Work (Form 1)File: CYNERGY - Thane.pdf | 17 Jul 2023 |
| Architect’s Certificate of Percentage of Completion of Work (Form 1)File: CYNERGY - Thane.pdf | 17 Jul 2023 |
| Engineer’s Certificate on Cost Incurred on Project (Form 2)File: FORM 2 - Cnergy Thane - Jan 23 to Mar 23.pdf | 25 Apr 2023 |
| Disclosure of sold/ booked inventoryFile: Sheth Cnergy - Thane.pdf | 25 Apr 2023 |
| CA Certificate on Project Cost & Fund withdrawal (Form 3)File: FORM 3 - Cnergy Thane - Jan 23 to Mar 23.pdf | 25 Apr 2023 |
| Architect’s Certificate of Percentage of Completion of Work (Form 1)File: Form1-Cynergy-Ph1-Jan'23-Mar'23.pdf | 12 Apr 2023 |
| Disclosure of sold/ booked inventoryFile: Sheth Cnergy Thane.pdf | 2 Feb 2023 |
| Engineer’s Certificate on Cost Incurred on Project (Form 2)File: FORM - 2 CNERGY THANE.pdf | 18 Jan 2023 |
| CA Certificate on Project Cost & Fund withdrawal (Form 3)File: FORM - 3 CNERGY THANE.pdf | 18 Jan 2023 |
| Architect’s Certificate of Percentage of Completion of Work (Form 1)File: Sheth Cnergy Thane.pdf | 12 Jan 2023 |
| Declaration about Commencement CertificateFile: Sheth Cnergy Form D 10-2-20.pdf | 28 Nov 2022 |
Promoter's earlier projects10
As disclosed by the promoter in this filing. Where a row names its RERA number, the project links to its own page and the location and registration date are read from that registration.
| Project | Location | Flats | Registered | Status | Promised | Delivered |
|---|---|---|---|---|---|---|
| SHETH BLUE IVYP51800001407 | DINDOSHI MALAD, Mumbai Suburban | 66 | Jul 2017 | Ongoing | Nov 2027Registered original: Jun 2023 | Not due yet |
| SIGMA | ZANDU PHARMACTICAL GOKHALE ROAD SOUTH DADAR W MUMBAI - 25 | 260 | - | Completed | Jul 2014 | Late, Dec 2014 |
| VIVIANA MALL | Viviana Mall Voltas Compound Pokharan Rd No 2 Majiwade Thane w 400601 | 240 | - | Completed | May 2013 | May 2013 |
| Vasant Lawns | Vasant Lawns Voltas Compound Pokharan Rd No 2 Majiwade Thane w 400601 | 465 | - | Completed | Mar 2012 | Late, Nov 2013 |
| VASANT MARVEL | WESTRN EXPRESS HIGHWAY BORIWALI EAST MUMBAI - 66 | 641 | - | Completed | Oct 2011 | Late, Jul 2012 |
| CNERGY | APPASAHEB MARATHE MARG PRABHADEVI MUMBAI 25 | 33 | - | Completed | Sep 2011 | Sep 2011 |
| BEAUMONDE | APPASAHEB MARATHE MARG PRABHADEVI MUMBAI 25 | 196 | - | Completed | Jul 2011 | Late, Jan 2012 |
| VASANT GALAXY | JUNCTION OF MG ROAD AND LINK ROAD BANGUR NAGAR GOREGAON WEST MUMBAI | 803 | - | Completed | Oct 2010 | Late, Mar 2011 |
| VASANT VALLEY | MALAD EAST MUMBAI 96 | 127 | - | Completed | Jun 2010 | Late, Dec 2010 |
| VASANT GARDEN | SWAPNA NAGARI OFF LBS MARG MULUND WEST MUMBAI 80 | 1,825 | - | Completed | Mar 2007 | Late, Dec 2007 |
Comparing a few projects?
You have opened several on ReraGenie. A free account keeps them in one list with their booking and possession figures, and puts two to six of them side by side.
How this compares with Thane
Computed across the 7,600+ Thane projects on ReraGenie, from their own filings.
Free monthly report: Thane on MahaRERA, month by month. What registered each month, this city against the other six, the possession pipeline and the pincode micro-markets, from these same filings.
Buyer report
Built from this project's filings on the day you order, in plain language.
- 5 conditions on this project's record read and explained, with the clear checks alongside
- Joined against the promoter's 9 other registrations and every project registered within 2 km, which the RERA portal never shows together
- All 133 filed documents as one ZIP, foldered, with a manifest
- The project watch below, included free for 90 days
Project watch
Only want to be told when something changes?
- An email each time this filing moves: new sales, a moved possession date, an extension, a complaint, the occupancy certificate
- Plain words, conditions that have happened marked in red
- A summary of everything that changed when the 90 days end
Keep SHETH CNERGY PH 1 - UPTO 11TH FLOOR on your shortlist
Saving puts this project on your dashboard with its booking and possession figures, ready to place side by side with up to five others. A free account also gets our weekly market digest by email.
Other projects near PANCH PAKHADI7,600+ in Thane
Filed coordinates, straight-line distance. 401 registered projects within 2 km.
ASHAR PULSE
Ms ASHAR VENTURES
SHETH ZURI
Sheth Developers Private Limited
Jagdale Edge
JAGDALE INFRASTRUCTURE PVT. LTD.
Bliss
Kapstone Constructions Private Limited
RUSTOMJEE LA VIE Wing D
Kapstone Constructions Private Limited
Thane Project
LODHA DEVELOPERS LIMITED
See every Thane project, with the district possession charts
Builder: Sheth Developers Private Limited
Sheth Developers Private Limited has 10 registrations on MahaRERA, including VASANT FIONA and CLARION. Its filings disclose 11 earlier MahaRERA projects: declares 2 of 9 past projects completed on time. Litigation is declared on 4 of its registrations. Read the full track record. See more projects on the Thane district page.
Frequently asked questions
What are my rights if SHETH CNERGY PH 1 - UPTO 11TH FLOOR is delayed beyond 28 Dec 2027?
Under section 18 of the RERA Act you may stay in the project and claim interest for every month of delay, or exit and claim a full refund with interest. In Maharashtra the rate is SBI's highest MCLR plus 2 percent, currently 10.90% per annum (June 2026). The free delay interest calculator on ReraGenie puts a rupee figure on any delay. Claims are filed as MahaRERA complaints with a Rs 5,000 fee.
How do I verify and contact the developer of SHETH CNERGY PH 1 - UPTO 11TH FLOOR?
The registered promoter entity is Sheth Developers Private Limited, a company as per the filing. Its CIN U45200MH1993PTC070335 can be cross-checked on the MCA and GST portals. Your agreement for sale must name this exact entity, not a group brand name. The promoter's registered address and contact details are on the project's MahaRERA listing (scan the QR code on any advertisement) and in its filed documents. The Rs 499 buyer report includes all of them as a single ZIP, foldered by type.
Is my payment protected in SHETH CNERGY PH 1 - UPTO 11TH FLOOR?
Partly, by law. 70 percent of every buyer payment must go into the project's designated bank account, withdrawable only against architect, engineer and CA certificates as construction progresses; since July 2024 MahaRERA requires a three-account structure for collections. Separately, a promoter cannot take more than 10 percent of the price before signing a registered agreement for sale (section 13). Neither rule guarantees completion; they limit how far your money can travel from the project.
How do I read the complaint cases filed against SHETH CNERGY PH 1 - UPTO 11TH FLOOR?
Each case number above is a complaint MahaRERA hears in public. On the MahaRERA website, open Complaint Details and search the CC number: the order PDFs, hearing dates and disposal status are free to download. Orders bind the promoter. Before booking, check whether past orders were complied with, not just whether complaints exist; an ignored order is a stronger warning than the complaint itself.
How current is the construction progress shown for SHETH CNERGY PH 1 - UPTO 11TH FLOOR?
Promoters must file a quarterly progress report within 20 days of each quarter end, certified by the architect (Form 1), engineer (Form 2) and chartered accountant (Form 3). The figures above come from the latest filing, so they can trail the site by up to a quarter. A promoter who stops filing QPRs altogether invites penalties under section 61, and a stale filing date is itself a warning sign worth checking on the portal.
Who certifies construction progress at SHETH CNERGY PH 1 - UPTO 11TH FLOOR?
The professionals named in the filing: Architect: Bipin Nannaware; Architect: TEN FOLDS ARCHITECTS AND CONSULTANTS; Engineer: Muhammad Shoeb Chouhan; Engineer: Umesh N Tripathi; Engineer: Smarty Lachhwani; Engineer: Anas Shaikh. Their Form 1 (architect), Form 2 (engineer) and Form 3 (chartered accountant) certificates are what unlock the promoter's withdrawals from the 70 percent account, so their names on record are part of the project's accountability chain.
What should I check before booking in SHETH CNERGY PH 1 - UPTO 11TH FLOOR?
Four things this page cannot decide for you: that the carpet area in your agreement matches the filed carpet area (the model agreement allows only a 3 percent variation, with a refund right below that); that the agreement follows MahaRERA's model clauses with deviations highlighted; how the declared litigation on this registration affects your risk; why the completion date was revised and what the new timeline depends on. The Rs 499 buyer report works through all of them from the filings.
Get the buyer report · Rs 499 See a real one first
Studying this micro-market rather than buying a flat? The developer project analysis, Rs 2,999, maps every registration within 5 km from filed coordinates, reads what this market absorbs, prices the parcel and takes the promoter's whole book apart. See a complete sample.
Spotted something wrong on this page, or want to tell us what would make it more useful? Every page here is built from what the promoter filed on MahaRERA, and we read every report.
Report an error Share feedback