Home / Browse projects / Pune, Maharashtra / Solitaire Business Hub Baner
Solitaire Business Hub Baner
RG-MH-23932 · RERA P52100008740 · Last updated on MahaRERA portal: 19 Aug 2026
Source: official MahaRERA filing
Or get an email each time it changes, with the project watch
Red flags
- 21 complaints at MahaRERA
- Completion date moved by 41 months
- 4 extensions taken
- Rs 50.00 crore secured on the land, in favour of Aditya Birla Finance Ltd
Clear
- No litigation declared
- Separate project account declared
- Allotment letter follows the model form
- All 1 earlier projects delivered on promise
4 conditions are on this record. What each one means for someone buying here, and what the promoter's own filed documents say behind it, is what the buyer report adds.
See what the report covers Free either way: or have every new Pune registration emailed to you, free during the pilot beta.Saved. When you are ready to decide, the Rs 499 buyer report reads the fine print for you.
Solitaire Business Hub Baner is a Commercial project by Atul Builders in Pune, Maharashtra, registered with MahaRERA as P52100008740 on 19 Aug 2017. Possession is promised by 6 Nov 2026. The completion date has moved by 41 months from the original filing. 240 of the 269 units on this registration are recorded sold or booked, and 36 of 44 construction stages are filed complete. 21 complaints are on record with the regulator.
At a glance
Project
- NameSolitaire Business Hub Baner
- TypeCommercial
- Location
- Mumbai Banglore Highway
- Baner
- Haveli
- Pune
- 411045
- Pincode411045
- MapView location on Google Maps (as filed on RERA)
- RERA no.P52100008740
- ReraGenie IDRG-MH-23932
Key dates
Key facts
Registration and timeline
- StatusRegistered
- Registered on19 Aug 2017
- Promised completion6 Nov 2026
- Revised completionRevised to 6 Nov 2026 (originally 30 Jun 2023)
- Buildings4 building records
- Documents filed239 files
Current status
Figures as on 19 Aug 2026, this project's latest MahaRERA filing.
Buildings and wings, as sanctioned
| Building | Wing | Floors sanctioned | Habitable floors | Residential units | Other units | Total |
|---|---|---|---|---|---|---|
| Building 1 - Ground to Third Floor | NA | 9 | 0 | 0 | 70 | 70 |
| Building 3 Sixth to Eighth Floor | NA | 3 | 3 | 0 | 67 | 67 |
| Building 2 - Fourth to Fifth Floor | NA | 2 | 2 | 0 | 44 | 44 |
| Building 4 - 9th Floor to 12th Floor | NA | 4 | 3 | 0 | 88 | 88 |
The full filing
Everything below is from the project's own MahaRERA filing, free to read. The Rs 499 buyer report reads the filed documents themselves and puts the findings in plain language.
Construction progress by building4
As on 19 Aug 2026, the date of the latest filing. The RERA activity checklist for each building, from the promoter's latest quarterly progress filing. These are the promoter's own figures, not an independent inspection.
36 of 44 construction stages are filed complete across 4 buildings. The stage furthest along is Podiums (if any), at 0%.
Building 1 - Ground to Third Floor82%
| Activity | Progress |
|---|---|
| Excavation | 100% |
| Basement (if any) | 100% |
| Podiums (if any) | 0% |
| Plinth | 100% |
| Stilt Floor | 0% |
| Slabs of Super Structure | 100% |
| Internal walls, Intemal Plaster, Floorings, Floors and windows within Flats/Premises | 100% |
| Sanitary Fittings within the flats / premises | 100% |
| Staircases, Lifts Wells and Lobbies at each Floor level Overhead and Underground Water Tanks | 100% |
| External plumbing and external plaster, elevation, completion of terraces with waterproofing of the Building / wing. | 100% |
| Installation of Lifts, water pumps, Fire Fighting Fittings and Equipment as per CFO NOC, Electrical fittings, mechanical equipment, compliance to conditions ofenvironment/CRZ NOC, Finishing to entrance lobby/s, plinth protection. paving of areas appurtenant to Building/Wing, Compound Wall and all other requirements as may be required to complete project as per specifications in agreement of Sale. | 100% |
Building 3 Sixth to Eighth Floor82%
| Activity | Progress |
|---|---|
| Excavation | 100% |
| Basement (if any) | 100% |
| Podiums (if any) | 0% |
| Plinth | 100% |
| Stilt Floor | 0% |
| Slabs of Super Structure | 100% |
| Internal walls, Intemal Plaster, Floorings, Floors and windows within Flats/Premises | 100% |
| Sanitary Fittings within the flats / premises | 100% |
| Staircases, Lifts Wells and Lobbies at each Floor level Overhead and Underground Water Tanks | 100% |
| External plumbing and external plaster, elevation, completion of terraces with waterproofing of the Building / wing. | 100% |
| Installation of Lifts, water pumps, Fire Fighting Fittings and Equipment as per CFO NOC, Electrical fittings, mechanical equipment, compliance to conditions ofenvironment/CRZ NOC, Finishing to entrance lobby/s, plinth protection. paving of areas appurtenant to Building/Wing, Compound Wall and all other requirements as may be required to complete project as per specifications in agreement of Sale. | 100% |
Building 2 - Fourth to Fifth Floor82%
| Activity | Progress |
|---|---|
| Excavation | 100% |
| Basement (if any) | 100% |
| Podiums (if any) | 0% |
| Plinth | 100% |
| Stilt Floor | 0% |
| Slabs of Super Structure | 100% |
| Internal walls, Intemal Plaster, Floorings, Floors and windows within Flats/Premises | 100% |
| Sanitary Fittings within the flats / premises | 100% |
| Staircases, Lifts Wells and Lobbies at each Floor level Overhead and Underground Water Tanks | 100% |
| External plumbing and external plaster, elevation, completion of terraces with waterproofing of the Building / wing. | 100% |
| Installation of Lifts, water pumps, Fire Fighting Fittings and Equipment as per CFO NOC, Electrical fittings, mechanical equipment, compliance to conditions ofenvironment/CRZ NOC, Finishing to entrance lobby/s, plinth protection. paving of areas appurtenant to Building/Wing, Compound Wall and all other requirements as may be required to complete project as per specifications in agreement of Sale. | 100% |
Building 4 - 9th Floor to 12th Floor82%
| Activity | Progress |
|---|---|
| Excavation | 100% |
| Basement (if any) | 100% |
| Podiums (if any) | 0% |
| Plinth | 100% |
| Stilt Floor | 0% |
| Slabs of Super Structure | 100% |
| Internal walls, Intemal Plaster, Floorings, Floors and windows within Flats/Premises | 100% |
| Sanitary Fittings within the flats / premises | 100% |
| Staircases, Lifts Wells and Lobbies at each Floor level Overhead and Underground Water Tanks | 100% |
| External plumbing and external plaster, elevation, completion of terraces with waterproofing of the Building / wing. | 100% |
| Installation of Lifts, water pumps, Fire Fighting Fittings and Equipment as per CFO NOC, Electrical fittings, mechanical equipment, compliance to conditions ofenvironment/CRZ NOC, Finishing to entrance lobby/s, plinth protection. paving of areas appurtenant to Building/Wing, Compound Wall and all other requirements as may be required to complete project as per specifications in agreement of Sale. | 100% |
Progress on shared amenities15
As on 19 Aug 2026, the date of the latest filing. Lifts, roads, water and the other shared works, from the same quarterly filing, and reported by the promoter rather than inspected.
| Common facility | Proposed | Progress |
|---|---|---|
| Internal Roads & Footpaths | Yes | 100% |
| Water Supply | Yes | 100% |
| Sewerage (Chamber, Lines, Septic Tank , STP) | Yes | 100% |
| Storm Water Drains | Yes | 100% |
| Landscaping & Tree Planting | Yes | 100% |
| Street Lighting | Yes | 100% |
| Community Buildings | No | Not applicable |
| Treatment And Disposal Of Sewage And Sullage Water | Yes | 100% |
| Solid Waste Management And Disposal | Yes | 100% |
| Water conservation /Rain water harvesting | Yes | 100% |
| Energy managemcnt | Yes | 100% |
| Fire protection and fire safety requirements | Yes | 100% |
| Electrical meter room, sub-station, receiving station | Yes | 100% |
| Aggregate area of recreational Open Space | No | Not applicable |
| Open Parking | No | Not applicable |
Parking filed1580
Slots recorded per building wing in the filing. MahaRERA does not publish a two wheeler or four wheeler split, visitor parking, or the sanctioned allotment, so this is provision as filed and not a comparison against the approved plan.
Land and ownership1
MahaRERA does not publish landowner contact details. A declared charge means a lender has a claim over the project land. Ask the promoter for a no-objection certificate from the lender named above before you pay any amount.
| Landowner | Village | District |
|---|---|---|
| M/s Creative Landmarks | Pune (M Corp.) | Pune |
Approvals and building plan
Project account and cost
70 percent of buyer money must sit in the project account. Account numbers are not published by MahaRERA, so check that your agreement for sale names a designated account for this project and pay into that account only.
| Building | Wing | Estimated | Incurred |
|---|---|---|---|
| Building 1 - Ground to Third Floor | NA | Rs 55.96 cr | Rs 57.26 cr |
| Building 4 - 9th Floor to 12th Floor | NA | Rs 33.11 cr | Rs 33.88 cr |
| Building 3 Sixth to Eighth Floor | NA | Rs 24.93 cr | Rs 25.51 cr |
| Building 2 - Fourth to Fifth Floor | NA | Rs 16.47 cr | Rs 16.85 cr |
| - | NA | Rs 12.82 cr | Rs 12.82 cr |
Certifying professionals and partners9
Form 1, 2 and 3 certificates from these professionals release the promoter's withdrawals from the 70 percent account.
| Role | Name |
|---|---|
| Architect | StudioSA |
| Architect | ANA Consortium Pvt. Ltd. |
| Architect | Venkataramanan Associates |
| Engineer | G A Bhilare Consultants Private Limited |
| Engineer | Swapnil Sonawane |
| Chartered Accountant | Bogati & Company |
| Chartered Accountant | GMKS & Co. |
| Chartered Accountant | RSVA & Co |
| Chartered Accountant | SPAK & Co |
| Partner | Role in project |
|---|---|
| Atul Builders | - |
Extensions applied for4
A revised date filed with the regulator does not change the possession date in your agreement for sale.
Reason as filed by the promoterdue to the covid 19 pandemic, we were not able to construct anymore because of lack of labour contractors and the poor market conditions we were unable to complete the project within the due time.
Reason as filed by the promoterThe construction and development of the said Project started as per the timelines under RERA. However, the project got delayed due to the effect of Covid-19 pandemic, wherein the Government declared nationwide lockdown entire nation suffered a global pandemic i.e., Covid-19 pandemic and various circular orders were passed due to which the construction and development of the said Project stalled, we faced several challenges that adversely affected the construction activities and the project got delayed due to major challenges i.e., disruption of supply chains for procuring construction material
Reason as filed by the promoterWe, Atul Builders, are developing a commercial project under the name and style “Solitaire Business Hub Baner,” which is registered under the Real Estate (Regulations and Development) Act, 2016 (“RERA”), bearing Project Registration Number P52100008740. We had applied for a RERA extension on 7th June 2024 via Application No. EXT52100022949 for one year under Section 7(3), as per Order 40/2022 & 40A/2023. During the extension hearing, we requested Hon’ble Chairperson Shri Manoj Saunik to grant an extension of one and a half years. Our request was approved, and as per the Rozanama dated 10th Dec
Reason as filed by the promoterWe hereby apply for extension of registration of the following project “Solitaire Business Hub Baner”, registered with the regulatory authority vide project registration certificate bearing No. P52100008740, which is expired on 31/12/2025. We respectfully submit that the project has already received the Full Occupation Certificate on 12/12/2025 bearing OC No. OCC/0978/25, and the same was submitted to MahaRERA through a Completion Application. However, during scrutiny, certain observations were raised regarding mismatch of the Built-up Area (BUA) and building details with the Occupation Certif
Complaints filed with MahaRERA21
| Case no. | Complainant | Respondent | Filed |
|---|---|---|---|
| CC005000000167626 | Shyam Manohar Juriasinghani | Atul Builders | 29/12/2022 |
| CC005000000064676 | Smaran Choudhury | atul builders and ronisun realty | 28/09/2020 |
| CC005000000259290 | DHANANJAY TUKARAM KATE | Atul Builders | 24/08/2023 |
| CC005000000279787 | Snehlata Jain | Atul Builders | 02/01/2024 |
| CC005000000279791 | Vaibhav Gupta | Atul Builders | 29/11/2023 |
| CC005000000290109 | Sagar Kapile | Atul Builders | 18/01/2024 |
| CC005000000370924 | FUSION SPACES LLP | Atul Builders | 24/05/2024 |
| CC12400129 | Sachin Dhorage | Atul Builders | 17/09/2024 |
| CC12400380 | Vishwajit Patil | Atul Builders | 09/10/2024 |
| CC12400556 | MAHENDRA MADHODAS MUNDADA | ATUL BUILDERS | 24/10/2024 |
| CC12500375 | SWATI KAILASH KAKDE SWATI KAKDE | CREATIVE LANDMARKS | 04/02/2025 |
| CC12501593 | Subrahmanyam Kavuri | Atul Builders | 14/05/2025 |
| CC12501624 | ATUL AUGUSTINE GOVANDE | Atul Builders | 19/05/2025 |
| CC12502802 | Ajinkya Anant Khaiwale | Atul Builders | 09/08/2025 |
| CC12504025 | Rahul Garg | Atul Builders | 15/11/2025 |
| CC12504029 | Sudha Bhati | Atul Builders | 15/11/2025 |
| CC12504030 | Sudha Bhati | Atul Builders | 15/11/2025 |
| CC12601338 | Revanth Kaza | Atul Builders | 11/03/2026 |
| CC12601314 | CHITRA NILESH TAMBE | Atul Builders | 10/03/2026 |
| CC12603619 | Sunita Dixit | Atul Builders | 12/06/2026 |
| CC12605383 | Sachin Dhorage | Atul Builders | 22/08/2026 |
The permission chain
The permissions a project needs, in the order they happen, matched to MahaRERA's own document slots. A slot on the file means the promoter uploaded a document there; it is not proof the permission was granted, and the filing carries no issue dates. An empty slot is not proof an approval is missing.
- Legal title reportOn the file
A lawyer's report on who owns the land and what is registered against it.
uploaded 19 Oct 2021 - Layout approvalOn the file
The planning authority's approval of how the plots and buildings sit on the land.
uploaded 31 Dec 2025 - Building plan approvalOn the file
Sanction of the building plans themselves, filed as an IOD in Mumbai and as a plan approval elsewhere.
uploaded 31 Dec 2025 - Commencement CertificateOn the file
Permission to begin construction. On a plotted development the same slot carries the NA order instead.
uploaded 10 May 2023Confirm the Commencement Certificate covers the specific floor you are buying. - Occupancy CertificateOn the file
The legal go-ahead to move in. It comes at the end, so its absence on a project still under construction is expected.
uploaded 8 Aug 2024
Documents filed239
As listed on the registration, named by the MahaRERA slot each file was filed under, with the promoter's own file name beneath; the newest 80 of 239 are shown. The files themselves are available at source: open this registration on the MahaRERA portal. We publish what the filing says and never host the promoter's documents in place of it.
| Document | Uploaded |
|---|---|
| Withdrawal Update Form 1File: Form 1 - SBH Baner I_Mar 26 Signed.pdf | 19 Aug 2026 |
| Withdrawal Update Form 1File: Form 1 - SBH Baner I_Mar 26 Signed.pdf | 19 Aug 2026 |
| Withdrawal Update Form 1File: Form 1 - SBH Baner I - Jun 26.pdf | 19 Aug 2026 |
| Withdrawal Update Form 2File: Form 2- SBH Baner I_Mar 26.pdf | 19 Aug 2026 |
| Withdrawal Update Form 2File: Form 2- SBH Baner I_Mar 26.pdf | 19 Aug 2026 |
| Withdrawal Update Form 2File: Form 2 - SBH Baner - Jun 26.pdf | 19 Aug 2026 |
| Withdrawal Update Form 3File: Form-3_SBH Baner_Mar26.pdf | 19 Aug 2026 |
| Withdrawal Update Form 3File: Form-3_SBH Baner_Mar26.pdf | 19 Aug 2026 |
| Withdrawal Update Form 3File: Form 3 - SBH Baner - Jun 26.pdf | 19 Aug 2026 |
| Form 2A (FY 2025-2026)File: Form 2A- SBH Baner I_Mar 26.pdf | 8 Jun 2026 |
| Withdrawal Update Form 1File: Form 1- SBH Baner - Dec 2025.pdf | 20 Jan 2026 |
| Withdrawal Update Form 2File: Form 2- SBH Baner - Dec 2025 .pdf | 20 Jan 2026 |
| Withdrawal Update Form 3File: Form 3 - SBH Baner - Dec 2025.pdf | 20 Jan 2026 |
| Layout approvalFile: Layout.pdf | 31 Dec 2025 |
| Building plan approvalFile: Scan_3843-02.pdf | 31 Dec 2025 |
| Building plan approvalFile: Building Plan-03.pdf | 31 Dec 2025 |
| Building plan approvalFile: Building Plan-04.pdf | 31 Dec 2025 |
| Building plan approvalFile: Building Plan -05.pdf | 31 Dec 2025 |
| Building plan approvalFile: Building Plan -06.pdf | 31 Dec 2025 |
| Building plan approvalFile: Building Plan-07.pdf | 31 Dec 2025 |
| Building plan approvalFile: Building Plan-08.pdf | 31 Dec 2025 |
| Building plan approvalFile: Building Plan-09.pdf | 31 Dec 2025 |
| Building plan approvalFile: Building Plan-10.pdf | 31 Dec 2025 |
| Building plan approvalFile: Building Plan-11.pdf | 31 Dec 2025 |
| Withdrawal Update Form 1File: Form 1- SBH Baner I - Sept 2025.pdf | 16 Oct 2025 |
| Withdrawal Update Form 2File: Form 2- SBH Baner I - Sept 2025.pdf | 16 Oct 2025 |
| Withdrawal Update Form 3File: Form 3- SBH Baner I - Sept 2025.pdf | 16 Oct 2025 |
| Form 5 (FY 2024-2025)File: SBH Baner-Form 5-FY 24-25.pdf | 18 Sep 2025 |
| Withdrawal Update Form 1File: Form 1 - SBH Baner Jun 25.pdf | 30 Jul 2025 |
| Withdrawal Update Form 2File: Form 2 - SBH Baner Jun 25.pdf | 30 Jul 2025 |
| Withdrawal Update Form 3File: Form 3 - SBH Baner Jun 25_compressed.pdf | 30 Jul 2025 |
| Certificates of Architect (Form 1)(Mandatory for only ongoing project)File: Form 1- SBH Baner_ Mar 2025.pdf | 26 Apr 2025 |
| Certificates of CA (Form 3)File: Form 3 - SBH Baner - Mar 25.pdf | 26 Apr 2025 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: Form 2 - SBH Baner - Mar 25.pdf | 26 Apr 2025 |
| Disclosure of sold/ booked inventoryFile: Sold Disclosure - SBH Baner I - Mar 25.pdf | 26 Apr 2025 |
| Engineers Certificate on Quality Assurance (Form 2A FY 2023-24)File: Form 2A - SBH Baner - Mar 25.pdf | 26 Apr 2025 |
| Certificates of CA (Form 3)File: Form 3 - SBH Baner - Dec 24.pdf | 20 Jan 2025 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: Form 2 - SBH Baner - Dec 24.pdf | 20 Jan 2025 |
| Disclosure of sold/ booked inventoryFile: Sold Disclosure - SBH Baner- Dec 24.pdf | 20 Jan 2025 |
| Certificates of Architect (Form 1)(Mandatory for only ongoing project)File: Form 1 - SBH Baner - Dec 24.pdf | 18 Jan 2025 |
| Annual Audit Report of Statutory CA (Form 5) (FY 2023-24)File: SBH Baner - FY 23-24 - Form 5.pdf | 13 Dec 2024 |
| Certificates of CA (Form 3)File: Form 3 - SBH Baner - Sept 2024.pdf | 10 Dec 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: Form 2 - SBH Baner - Sept 2024.pdf | 10 Dec 2024 |
| Certificates of CA (Form 3)File: SBH BANER MAY 2020.pdf | 26 Nov 2024 |
| Certificates of CA (Form 3)File: SBH BANER SEPT 2021.pdf | 26 Nov 2024 |
| Certificates of CA (Form 3)File: SBH BANER JUNE 2021.pdf | 26 Nov 2024 |
| Certificates of CA (Form 3)File: 7Form 3 SBH Baner Jan 19.pdf | 14 Nov 2024 |
| Certificates of CA (Form 3)File: 6Form 3 SBH Baner Oct 18.pdf | 14 Nov 2024 |
| Certificates of CA (Form 3)File: 5Form 3 SBH Baner Aug 18.pdf | 14 Nov 2024 |
| Certificates of CA (Form 3)File: 4Form 3SBH Baner May 18.pdf | 14 Nov 2024 |
| Certificates of Architect (Form 1)(Mandatory for only ongoing project)File: Form 1 - SBH Baner - Sept 2024.pdf | 21 Oct 2024 |
| Disclosure of sold/ booked inventoryFile: Sold Discloure - SBH Baner - Sept 2024.pdf | 19 Oct 2024 |
| Certificates of CA (Form 3)File: Form 3 - SBH Baner - May 19.pdf | 8 Oct 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 2 Form 2 Nov 2017.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 3 Form 2 Feb 2018.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 4 Form 2 may 2018.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 5 Form 2 Aug 2018.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 6 Form 2 Oct 2018.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 7 Form 2 Jan 2019.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 8 Form 2 May 2019.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 9 Form 2 Aug 2019.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 10 Form 2 Nov 2019.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 11 Form 2 Feb 2020.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 12 Form 2 May 2020.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 13 Form 2 Aug 2020.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 14 Form 2 Nov 2020.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 15 Form 2 Feb 2021.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 16 Form 2 Jun 2021.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 17 Form 2 Sep 2021.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 18 Form 2 Dec 2021.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 19 Form 2 March 2022.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 20 Form 2 Jun 2022.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 21 Form 2 Sep 2022.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 22 Form 2 Dec 2022.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 23 Form 2 March 2023.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 24 Form 2 Jun 2023.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 25 Form 2 Sep 2023.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 26 Form 2 Dec 2023.pdf | 9 Aug 2024 |
| Certificates of Engineer (Form 2)(Mandatory for only ongoing project)File: 28 FORM 2 -Engineer certificate-SBH 1 Jun 24.pdf | 9 Aug 2024 |
| Certificates of CA (Form 3)File: 2 Form 3 SBH Baner Nov-17.pdf | 9 Aug 2024 |
Promoter's earlier projects1
As disclosed by the promoter in this filing. Where a row names its RERA number, the project links to its own page and the location and registration date are read from that registration.
| Project | Location | Flats | Registered | Status | Promised | Delivered |
|---|---|---|---|---|---|---|
| AVALON CITY C-3P52100003105 | Pune, Pune | 47 | Aug 2017 | Completed | Dec 2021Registered original: Dec 2019 | Feb 2020 |
Comparing a few projects?
You have opened several on ReraGenie. A free account keeps them in one list with their booking and possession figures, and puts two to six of them side by side.
How this compares with Pune
Computed across the 13,700+ Pune projects on ReraGenie, from their own filings.
Free monthly report: Pune on MahaRERA, month by month. What registered each month, this city against the other six, the possession pipeline and the pincode micro-markets, from these same filings.
Buyer report
Built from this project's filings on the day you order, in plain language.
- 4 conditions on this project's record read and explained, with the clear checks alongside
- Joined against the promoter's 2 other registrations and every project registered within 2 km, which the RERA portal never shows together
- All 239 filed documents as one ZIP, foldered, with a manifest
- The project watch below, included free for 90 days
Project watch
Only want to be told when something changes?
- An email each time this filing moves: new sales, a moved possession date, an extension, a complaint, the occupancy certificate
- Plain words, conditions that have happened marked in red
- A summary of everything that changed when the 90 days end
Keep Solitaire Business Hub Baner on your shortlist
Saving puts this project on your dashboard with its booking and possession figures, ready to place side by side with up to five others. A free account also gets our weekly market digest by email.
Other projects near Baner13,700+ in Pune
Filed coordinates, straight-line distance. 395 registered projects within 2 km.
EARTH 1 BY VTP LUXE PHASE 1
MAHALUNGE REAL ESTATE DEVELOPERS PVT. LTD.
Godrej Meadows
Mahalunge Township Developers Private Limi
Godrej Green Vistas
Mahalunge Township Developers Private Limi
Godrej Hill Retreat
Mahalunge Township Developers Private Limi
Godrej Green Cove
Mahalunge Township Developers Private Limi
NYATI EMERALD I
NYATI BUILDERS PRIVATE LIMITED
Builder: Atul Builders
Atul Builders has 3 registrations on MahaRERA, including Solitaire Nine and SOLITAIRE SEVEN. Its filings disclose 1 earlier MahaRERA project: declares 1 of 1 past projects completed on time. Read the full track record. See more projects on the Pune district page.
Frequently asked questions
What are my rights if Solitaire Business Hub Baner is delayed beyond 6 Nov 2026?
Under section 18 of the RERA Act you may stay in the project and claim interest for every month of delay, or exit and claim a full refund with interest. In Maharashtra the rate is SBI's highest MCLR plus 2 percent, currently 10.90% per annum (June 2026). The free delay interest calculator on ReraGenie puts a rupee figure on any delay. Claims are filed as MahaRERA complaints with a Rs 5,000 fee.
How do I verify and contact the developer of Solitaire Business Hub Baner?
The registered promoter entity is Atul Builders, a partnership as per the filing. Neither this filing nor this promoter's other MahaRERA registrations disclose a CIN, LLPIN or GSTIN for this entity. Your agreement for sale must name this exact entity, not a group brand name. The promoter's registered address and contact details are on the project's MahaRERA listing (scan the QR code on any advertisement) and in its filed documents. The Rs 499 buyer report includes all of them as a single ZIP, foldered by type.
Is my payment protected in Solitaire Business Hub Baner?
Partly, by law. 70 percent of every buyer payment must go into the project's designated bank account, withdrawable only against architect, engineer and CA certificates as construction progresses; since July 2024 MahaRERA requires a three-account structure for collections. Separately, a promoter cannot take more than 10 percent of the price before signing a registered agreement for sale (section 13). Neither rule guarantees completion; they limit how far your money can travel from the project.
How do I read the complaint cases filed against Solitaire Business Hub Baner?
Each case number above is a complaint MahaRERA hears in public. On the MahaRERA website, open Complaint Details and search the CC number: the order PDFs, hearing dates and disposal status are free to download. Orders bind the promoter. Before booking, check whether past orders were complied with, not just whether complaints exist; an ignored order is a stronger warning than the complaint itself.
How current is the construction progress shown for Solitaire Business Hub Baner?
Promoters must file a quarterly progress report within 20 days of each quarter end, certified by the architect (Form 1), engineer (Form 2) and chartered accountant (Form 3). The figures above come from the latest filing, so they can trail the site by up to a quarter. A promoter who stops filing QPRs altogether invites penalties under section 61, and a stale filing date is itself a warning sign worth checking on the portal.
Who certifies construction progress at Solitaire Business Hub Baner?
The professionals named in the filing: Architect: StudioSA; Architect: ANA Consortium Pvt. Ltd.; Architect: Venkataramanan Associates; Engineer: G A Bhilare Consultants Private Limited; Engineer: Swapnil Sonawane; Chartered Accountant: Bogati & Company. Their Form 1 (architect), Form 2 (engineer) and Form 3 (chartered accountant) certificates are what unlock the promoter's withdrawals from the 70 percent account, so their names on record are part of the project's accountability chain.
What should I check before booking in Solitaire Business Hub Baner?
Four things this page cannot decide for you: that the carpet area in your agreement matches the filed carpet area (the model agreement allows only a 3 percent variation, with a refund right below that); that the agreement follows MahaRERA's model clauses with deviations highlighted; the promoter's record on their other projects, not just this one; why the completion date was revised and what the new timeline depends on. The Rs 499 buyer report works through all of them from the filings.
Get the buyer report · Rs 499 See a real one first
Studying this micro-market rather than buying a flat? The developer project analysis, Rs 2,999, maps every registration within 5 km from filed coordinates, reads what this market absorbs, prices the parcel and takes the promoter's whole book apart. See a complete sample.
Spotted something wrong on this page, or want to tell us what would make it more useful? Every page here is built from what the promoter filed on MahaRERA, and we read every report.
Report an error Share feedback